Terms and Conditions for Create My Designs

Welcome to Create My Designs. These Terms and Conditions ("Terms") govern your access to and use of our website, services, and communications. By accessing our website or engaging our services, you agree to be bound by these Terms.

If you do not agree with these Terms, please do not use our website or services.

1. Our Services

Create My Designs provides professional digital services, including but not limited to:

• Website Design
• Website Development
• E-commerce Website Development
• Search Engine Optimization (SEO)
• Social Media Optimization (SMO)
• Pay-Per-Click (PPC) Marketing
• Digital Marketing
• Branding & Graphic Design
• Logo Design
• Mobile Application Development
• Video Animation
• Website Maintenance
• Other creative and digital consulting services

Services may change or expand without prior notice.

2. Client Responsibilities

• Provide accurate project information.
• Supply all required content, images, logos, and branding materials.
• Ensure they own or have permission to use any materials they provide.
• Review and approve project milestones promptly.
• Make payments according to the agreed schedule.

Project delays caused by missing client information may affect delivery timelines.

3. Quotes & Pricing

All quotations are valid for the period specified in the proposal.

• Prices are subject to change before project confirmation.
• Additional work outside the agreed scope will be quoted separately.
• Changes requested after project approval may incur additional charges.

4. Payments

Payment terms will be outlined in each project proposal or invoice.

• A deposit may be required before work begins.
• Remaining payments must be made according to the agreed schedule.
• Late payments may delay project completion or suspend services until payment is received.

5. Project Revisions

Reasonable revisions are included only if specified in your project agreement. Additional revisions or requests beyond the agreed scope may incur additional fees.

6. Project Timelines

Estimated completion dates are provided in good faith.

Delivery schedules may be affected by:

• Client feedback delays
• Content delivery delays
• Third-party service interruptions
• Technical issues beyond our control

We will make reasonable efforts to keep projects on schedule.

7. Intellectual Property

• The client receives ownership of the final approved deliverables after full payment unless otherwise agreed.
• Create My Designs retains ownership of internal tools, templates, source code libraries, methodologies, and proprietary processes.
• Third-party software, plugins, fonts, images, or licensed assets remain subject to their respective licenses.

8. Portfolio Rights

Unless otherwise agreed in writing, Create My Designs reserves the right to display completed work in our portfolio, website, social media, and marketing materials.

If a project is confidential, the client must notify us before the project begins.

9. Third-Party Services

Projects may include:

• Website Hosting
• Domain Registration
• Payment Gateways
• Analytics Platforms
• Marketing Tools
• AI-powered Software
• Plugins & APIs

We are not responsible for service interruptions, pricing changes, or policy updates made by third-party providers.

10. Website Content

Clients are responsible for ensuring all supplied content complies with applicable laws and does not infringe the rights of others.

We reserve the right to refuse work involving illegal, misleading, defamatory, or offensive content.

11. Search Engine Optimization (SEO)

SEO results cannot be guaranteed. Rankings depend on algorithm changes, competition, website history, and ongoing maintenance.

12. Digital Marketing

Marketing performance depends on many external factors.

We cannot guarantee:

• Specific Rankings
• Lead Volume
• Sales
• Advertising Performance
• Social Media Growth

13. Limitation of Liability

Create My Designs shall not be liable for:

• Loss of profits
• Loss of business opportunities
• Data loss
• Website downtime
• Indirect or consequential damages
• Third-party software failures

Our total liability shall not exceed the amount paid by the client for the specific service giving rise to the claim.

14. Website Availability

We strive to keep our website available at all times but do not guarantee uninterrupted access due to maintenance, technical issues, or circumstances beyond our control.

15. Privacy

Your use of our website is also governed by our Privacy Policy. By using our website, you consent to the collection and use of information described therein.

16. Termination

We reserve the right to suspend or terminate services if:

• Payments remain overdue.
• A client breaches these Terms.
• Fraudulent or unlawful activity is suspected.
• Continued work becomes impractical due to client actions.

Completed work up to the termination date may remain payable.

17. Indemnification

You agree to indemnify and hold harmless Create My Designs from any claims, damages, liabilities, or expenses arising from materials supplied by you, copyright infringement, trademark infringement, or illegal use of our services.

18. Governing Law

These Terms shall be governed by the laws of India. Any disputes shall be subject to the jurisdiction of the courts located in Kolkata, West Bengal.

19. Changes to These Terms

We may update these Terms from time to time. Continued use of our website or services constitutes acceptance of the revised Terms.

20. Contact Us